Loading...
Serving Little Rock, AR and surrounding areas. (501) 401-9037
Effective date: January 1, 2026
By accessing the website at littlerockconcreteandmasonry.com or by engaging Ridgeline Little Rock Concrete & Masonry for any service, you agree to be bound by these Terms and Conditions. If you do not agree, please do not use this website or engage our services. We may update these terms from time to time. Continued use of the website or our services after changes are posted constitutes your acceptance of the revised terms.
Ridgeline Little Rock Concrete & Masonry is a masonry contractor providing services including, but not limited to, foundation repair, chimney repair, tuckpointing, brick repair, driveway pavers, retaining wall construction, masonry restoration, fireplace installation, stone veneer installation, concrete block walls, walkway construction, and related work.
All services are performed in AR and surrounding areas. The scope of work for any specific project is defined in a written proposal or contract provided to the customer before work begins.
Estimates provided by Ridgeline Little Rock Concrete & Masonry are based on the information available at the time of the site visit. An estimate is not a guaranteed final price. Final pricing may change if the scope of work changes, if conditions discovered during the project differ materially from what was visible at the time of the estimate, or if the customer requests modifications to the original scope.
Any change in scope or price will be communicated to the customer in writing before additional work proceeds. Verbal agreements regarding price changes are not binding on Ridgeline Little Rock Concrete & Masonry.
Scheduled appointments and project start dates are estimates based on crew availability and weather conditions. Ridgeline Little Rock Concrete & Masonry will make reasonable efforts to notify customers of delays in advance.
If you need to cancel or reschedule a confirmed appointment, please contact us as soon as possible. Cancellations made with less than 24 hours notice may result in a scheduling fee.
Work may be delayed or rescheduled due to weather, material availability, or other circumstances beyond our control. We are not liable for delays caused by factors outside our reasonable control.
Payment terms are outlined in the written proposal or contract for each project. For larger projects, a deposit may be required before work begins. The balance is due upon completion of the work unless otherwise specified in writing.
Accepted payment methods will be communicated at the time of the proposal. Payments not received by the due date may be subject to a late fee or may result in suspension of work until the account is brought current.
If a customer disputes any charge, they must notify Ridgeline Little Rock Concrete & Masonry in writing within 7 days of receiving the invoice. Disputes raised after that window may not be honored.
Ridgeline Little Rock Concrete & Masonry warrants that all work will be performed in a workmanlike manner consistent with industry standards. Specific warranty terms, including duration and coverage, are provided in writing with each project proposal or contract.
Warranties do not cover damage caused by factors outside of Ridgeline Little Rock Concrete & Masonry's workmanship, including but not limited to: acts of nature, soil movement beyond what is addressed in the scope of work, damage caused by other contractors, or failure by the customer to maintain the work as instructed.
To make a warranty claim, contact us in writing at projects@littlerockconcreteandmasonry.com with a description of the issue and photos where applicable. We will respond within a reasonable time to assess and address valid warranty claims.
Customers are responsible for:
To the maximum extent permitted by applicable law, Ridgeline Little Rock Concrete & Masonry is not liable for any indirect, incidental, consequential, or special damages arising out of or related to the services provided or the use of this website.
In no event shall Ridgeline Little Rock Concrete & Masonry's total liability for any claim related to a specific project exceed the total amount paid by the customer for that project.
The content on littlerockconcreteandmasonry.com is provided for informational purposes only. While we make reasonable efforts to keep information current and accurate, we make no guarantees about the completeness or accuracy of the information on this site.
You may not use this website for any unlawful purpose or in any way that could damage, disable, or impair the site or interfere with any other party's use of it. Unauthorized scraping, automated access, or reproduction of content from this site is prohibited.
If a dispute arises related to our services or these terms, we encourage you to contact us first to try to resolve it informally. Most concerns can be addressed quickly by reaching out directly:
projects@littlerockconcreteandmasonry.com
If informal resolution is not possible, disputes will be resolved through binding arbitration in Little Rock, AR, under the rules of the American Arbitration Association, unless both parties agree to an alternative process in writing.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of Arkansas, without regard to its conflict of law provisions. Any legal proceedings not subject to arbitration shall be brought in the courts of Arkansas.
Ridgeline Little Rock Concrete & Masonry reserves the right to update or revise these Terms and Conditions at any time. Changes will be posted on this page with an updated effective date. Your continued use of this website or our services after changes are posted indicates your acceptance of the revised terms.
Questions about these Terms and Conditions can be directed to:
Ridgeline Little Rock Concrete & Masonry
1501 S Spring St
Little Rock, AR 72202